The first page of this electrical services agreement template includes sections for contact information for your company and your client as well as a section to list any services included in this agreement.

Choose a Template. The first thing you need to do is to choose the right template. There are many contract templates in Word you can choose from as there is a huge variety of templates available. You must choose the right template as this contract is the face of the deal. Download Simple Contract Template for Free. FormTemplate offers you hundreds of resume templates that you can choose the one that suits your work experience and sense of design. You can also make a new resume with our online resume builder which is free and easy to use. For more forms or templates, please view Simple Contract Template on.

Prepared for:
[Client.FirstName][Client.LastName]
[Client.Company]

Created by:
[Sender.FirstName][Sender.LastName]
[Sender.Company]

Customer

Deliverables

The following services will be performed under the terms of this electrical services agreement

Payments

You can customize the template’s pricing table to reflect anything you’re planning to invoice the customer for, such as labor, taxes, or materials.

Payment due in full upon completion of the services listed above.

Name	Price	Qty	Subtotal

Subtotal	$0.00
Discount	$0.00
Tax	$0.00
Total	$0.00

Terms and Conditions

The terms in the template below are designed to protect the electrical services provider while remaining fair to your clients.

All electrical installation work will be performed in compliance with Federal, State, and Local guidelines and regulations.
If [Sender.Company] discovers a need for additional time or materials once the work has commenced, [Sender.Company] will seek written approval prior to continuing work.
Customer is responsible for providing unmitigated access to the work area. This includes moving any furnishings, wall-hangings, or other items which could prevent [Sender.Company] from carrying out the listed services.
All areas of installation will be left in the condition found unless otherwise stated in writing by Sender Name.
Client Name will provide accessible electricity to all working areas including outdoor areas. This includes proving a live power outlet or generator within 150 feet of the working area.
Sitework, including demolition or removal of debris, is not included in this electric services contract.

Deviations from Building Regulations

Following the terms in conditions in this electrical services agreement contract template are the exclusions. This protects you from certain faults and allows you to list any services not included in this agreement.

Where applicable, all work performed under this electrical services agreement will be executed fully in compliance with applicable Building Regulations and the National Electric Code. Where a Client requires deviation from such regulations, a written instruction and record will be required along with written approval from a governing authority.

Risk and Title of Goods & Property

All applicable goods and products installed will become property of the client on date of installation.
All goods not paid in full or remaining with customer will be property of the service provider until payment has been made or delivery has ensued.
Client is responsible for all insurance of dwellings and service location for entire time of work.

Warranty

Be sure to customize this section to reflect your company’s warranty policy.

[Sender.Company] has, to the best of their knowledge has provided installation and quality parts for overall best quality of product. Furthermore all parts will be warrantied for a 12 month period after installation for any technical defects.

Acceptance

Once this template has been customized to your liking, your client will be able to view and sign the final electrical services agreement draft from their computer, smartphone, or tablet.

By signing below, Customer understands and accepts all terms and conditions outlined in this electrical services agreement.

[Client.Company]

Signature

MM/DD/YYYY

A construction contract is an agreement between a client and a contractor that specifies the details of a construction project. The details in a construction contract should include all aspects of the project, including payment, the type of work being done, legal rights of the contractor, and more.

For some types of construction projects, you may need government permits in addition to the construction contract before contractors can begin working.

Table of Contents

1. What is a Construction Agreement?

A Construction Contract Agreement is a written document between a property owner and a general contractor, specifying the construction, renovations, alterations, or other work to be done on the property owner’s home or land. This document outlines which parties will be engaged, the price to be paid, the rights of each party, and the date construction will commence and be completed.

A simple document will identify the following basic elements:

Owner: The party hiring the general contractor to complete construction on his or her property.
General contractor: The party responsible for the day-to-day oversight of the construction.
License number: The general contractor’s state license board number, proving they are a licensed contractor
Worksite: The address of the property where the construction is to be completed.
Description of work: A detailed description of the work and construction to be done by the contractor. You can also attach project plans and specifications to the agreement.
Contract price and payments: The total price to be paid for the work and how and when payments will be made.
Contract documents: any drawings, blueprints, exhibits or other documents that will part of the contract
Materials and labor: Which party will supply and pay for the cost of materials and labor.
Starting and completion dates: The dates the contractor must start construction and have the construction substantially completed by.
Licensing and permits: Which party will be responsible for obtaining any required licenses and permits.
Subcontracts: Whether the contractor will hire subcontractors to help perform part of the contractor’s obligations
Work changes: How any changes to the agreed upon work will be handled once construction has begun.
Warranties: How long will the contractor warrant that his or her work is free from material defects.

These additional elements can also be included:

Indemnification: The contractor promises to be responsible for any loss or damages incurred by the owner arising out of his or her work.
Dispute resolution: Arbitration, mediation, and adjudication are common ways for parties to settle disputes under the contract instead of going through the courts.
Termination: When the buyer or contractor can terminate the contract.
Inspection: Allows the owner to examine the work done by the contractor at any time during construction to see if it conforms with the contract terms.
Insurance: Owners and contractors are both responsible for obtaining insurance to protect against damages and defects, and claims and losses.
Liquidated damages: An amount per day that the contractor must pay to the owner for each day past the agreed

Installation Contract Template Free